Web Developer Terms of Service
Last Updated: 8/28/23
Welcome to my web development services! I’m excited to work with you on your web development needs. Please read these Terms of Service carefully before using web development services.
By engaging with services, you agree to the following terms and conditions:
1. Services Offered:
Offering freelance web development services, which include designing, developing, and maintaining websites according to your requirements.
2. Communication:
Clear and effective communication is vital for a successful project. Keep you updated on the progress, and you agree to provide timely feedback and necessary information.
3. Project Scope:
We will define the scope of the project in a written agreement, outlining the deliverables, timeline, and costs. Any changes to the scope will require mutual agreement and may result in additional fees.
4. Payment:
Payment details will be outlined in the project agreement. A deposit may be required before work commences. Full payment for each milestone or project is due upon completion, unless otherwise agreed upon.
5. Confidentiality:
To treat all information you provide as confidential. Any sensitive information shared during the project will not be disclosed to third parties.
6. Intellectual Property:
Upon full payment, you will own the intellectual property rights to the final deliverables. We retain the right to showcase the project in our portfolio and marketing materials.
7. Revisions and Changes:
We strive to meet your expectations. A specified number of revisions will be included in the project agreement. Additional revisions may incur extra charges.
8. Delays:
Delays caused by factors beyond our control (e.g., client feedback delay, third-party services) may impact project timelines. We will do our best to communicate any potential delays promptly.
9. Termination:
Either party may terminate the project with written notice if the other party breaches these terms. You agree to compensate for work completed up to the termination date.
10. Limitation of Liability:
We will perform our services with care and professionalism. However, we are not liable for any losses, damages, or expenses arising from the use or inability to use the deliverables.
11. Indemnification:
You agree to indemnify and hold us harmless from any claims, damages, or liabilities arising from your use of the deliverables or any breach of these terms.
12. Governing Law:
These terms are governed by the laws. Any disputes shall be subject to the exclusive jurisdiction of the courts.
13. Modifications:
We reserve the right to modify these terms at any time. Any changes will be communicated to you and will apply to future projects.
By proceeding with our services, you acknowledge that you have read, understood, and agreed to these Terms of Service. If you have any questions or concerns, please contact me at [email protected].
Thank you for choosing me for your web development needs! Looking forward to collaborating with you on your project.